000			04454aaa a2200301 i 4500
005			20211224125533.0
008			211024s2020 ua ||||| |||| 00| 0 eng d
040			_aID _cID _drda
041	1		_aeng _aara
082			_2ID _a109.6 _bPublic Entities
110	2		_aEgypt
245	1	4	_aThe executive regulations of Law No. 182 of the year 2018 regulating the contracts concluded by public entities / _cTranslated by The middle east library for economic services.
246	3	1	_aاللائحة التنفيذية لقانون تنظيم التعاقدات التي تبرمها الجهات العامة _dCode 29/D/1
264			_aCairo : _bThe middle east library for economic services, _cApril 2020.
300			_a128, 86 page ; _c30 cm.
336			_2rdacontent _atext
337			_2rdamedia _aunmediated
338			_2rdacarrier _avolume
500			_aSerial No. 41/2020
505	0		_aLaw No. 692 of the year 2019: Promulgating the Executive Regulations of the law regulating the contracts concluded by public entities Part -1: General provisions - Chapter - 1: Definitions - Chapter - 2: Institutional organization of government contracts - Chapter - 3: General principles Part-2: Principles of contracting Part -- 3: General rules of solicitation and contracting – Chapter - 1: Pre-solicitation stage - Section - 1: Sustainable contracting, requirements plan, and contract planning - Section - 2: Compliance with the requirement of having the necessary appropriations, permits and licenses - Section - 3: Request for information, and request for expression of interest - Section - 4: Drawing up technical specifications - Section - 5: Market study, basis of setting the estimated value or upset price - Section - 6: Bid bond and its forms, and notice of solicitation - Section - 7: Tenders specifications – Chapter - 2: Solicitation stage - Section - 1: Announcement or invitation - Section - 2: Prequalification - Section - 3: Clarifications and inquiries - Section - 4: Preparation, presentation and safekeeping of bids - Section - 5: Technical envelop - Section - 6: Financial envelop - Section - 7: Death of bidder and sub-contracting - Section - 8: Contracting with the administrative entity's workers, validity of bids - Chapter - 3: Awarding and contracting stage Section - 1: Committees - Section - 2: Awarding and contracting provisions - Subsection-1: Technical adjudication procedures - Subsection-2: Procedures for financial adjudication - Subsection-3: Awarding and winning bidder notification - Subsection-4: Performance bond - Subsection-5: Prohibition of submitting more than one bid, prohibition of bid amendment, disagreement settlement, and clarification of non-acceptance reasons Chapter- 4: Contract implementation stage - Section - 1: Contract execution and management - Section -2: The general rules for disbursement and payment - Section - 3: Down payment and the disbursement of payments in advance - Section - 4: Entitlements collection - Section - 5: Amendment of the contract size or value - Section – 6 Delay in contract implementation and delay in taking over the works - Section - 7: Mandatory or discretionary termination of the contract and the contractors' death. Chapter -5: Terms of the contract implementation - Section- 1: General terms of the contract implantation - Section -2: Implementation terms of the contracts for the supply of movables and takeover of properties - Section -3: Conditions of implementation of construction works Contracts Part -4: On purchase or lease of movables and immovable properties and contracting on construction works, receipt of services, technical works and consultancy studies Part-5 On sale and lease of movables and immovable properties and projects not having corporate personality and license of usufruct or utilization of immovable properties and projects Part 6: Contracts of special provisions Chapter-1: Contracting on consultancy studies - Chapter -2: Contracting with basic services providers and small projects - Chapter - 3: Contracts based on private sector initiative and transaction Part-7: Final and miscellaneous provisions
546			_aText in English and arabic.
650		0	_aPublic Entities _zEgypt _xcontracts _xLaw and Legislations
651		0	_aEgypt _xLaw and Legislations
710	2		_aThe middle east library for economic services, _etranslator.
901			_a110/108
902			_acataloger2
942			_2ddc _cCODEEN
999			_c3136 _d3136